Date Issue   Judgment 11.11.98 Whether sums obtained by settlement can serve as the correct measure of damage in third party proceedings   P&O Developments Limited -v-The Guy's and St Thomas' National Health Service Trust 07.10.98 Assessment of damages in contribution proceedings and "loss of chance" in causation   Sainsbury -v- Broadway Malyan and Ernest Green Partnership Ltd 30.09.98 Third party liability under the Civil Liability (Contribution) Act 1978   J. Sainsbury Plc -v- Broadway Malyan and Ernest Green Partnership 23.09.98 Award of damages for infringement of designer's copyright   Redrow Homes Limited -v- Bett Brothers Plc 26.08.98 Claims notification provisions   Alfred McAlpine Plc -v- BAI (Run-Off) Ltd 12.08.98 Formula based approach to the calculation of head office overheads   Norwest Holst Construction -v- Co-operative Wholesale Society 15.07.98 Recovery of economic loss in tort   Tunnel Refineries Ltd -v- Bryan Donkin Ltd and Others 08.07.98 Global costs claims   Inserco Ltd -v- Honeywell Control Systems 10.06.98 Payment of off-site overheads and profit in the event of delay   City Axis Ltd -v- Daniel P Jackson 28.05.98 Waiver of entitlement to damages and equitable estoppel   Keller Ltd -v- Morrison/Bilfinger Berger 13.05.98 The measure of damages in connection with defective works   George Fischer Ltd -v- Multi Design Consultants and Davis Langdon & Everest 08.04.98 ICE clause 12 ground condition claims and remoteness of damage   Humber Oil Terminal Trustees Ltd -v- Owners of the Ship "Sivand" 11.03.98 Whether the Court will exercise its discretion under the 1950 Arbitration Act for the appointment of an arbitrator in the event of inexcusable delay by the Plaintiff   HM Secretary of State for Foreign and Commonwealth Affairs -v- The Percy Thomas Partnership and Kier International Ltd 14.01.98 Whether a claim in respect of delayed costs can be applied as an abatement against a claim for payment by a sub-contractor   Mellows Archital Ltd -v- Bell Projects Ltd 26.11.97 Causation in the context of claims for damages   Scandia Property (UK) Ltd - v- Thames Water Utilities Ltd 19.11.97 Refusal to pay for works carried out defectively   Barrett Steel Building Ltd -v- AMEC Construction Ltd. 27.08.97 Pleading of global claims   Bernards Rugby Landscapes-v-Stockley Park Consortium Limited 18.06.97 Pricing of works where quantities alter from billed quantities   Mitsui Construction Co Ltd v The Attorney General of Hong Kong 26.02.97 Payment of quantum meruit where no contract in place   Costain Tarmac Joint Venture -v- Zanen Dredging and Contracting 19.02.97 Whether a settlement between client and main contractor may be taken as the measure of damages in the related dispute with a sub-contractor   Spirotec Engineering Ltd -v- Chiltern Engineering Ltd 15.01.97 Recovery of fixed overheads and profit on delayed projects   Amec Building Ltd -v- Cadmus Investment Company Ltd 07.11.96 Reimbursement of head office overheads and profit during period of delay   St Modwen Developments Ltd -v- Bowmer and Kirkland Ltd 31.10.96 Valuation of profit and attendance items on provisional sums   St Modwen Developments Limited -v- Bowmer and Kirkland. 24.10.96 Quantum of damages for negligent valuation   South Australia Asset Management Corporation -v- York Montague Limited 15.08.96 Pleading of case for contribution from subcontractors and subconsultants against contingent liability to building owner   Alfred McAlpine Construction Ltd -v- Hannah Reed and Others 25.07.96 Distinction between set-off and counterclaim, and raising a new action following settlement   Hoppe -v- Titman 18.04.96 The defence of abatement in professional services agreements   Foster Wheeler Group Engineering Ltd -v- Chevron UK Ltd 01.02.96 Recovery of head office overheads during periods of project delay   Alfred McAlpine Homes North Ltd -v- Property and Land Contractors For other Articles in Claims click below 1999-2005