Cases by Year - 2009
 

49 cases found.

Date Issue   Judgment
16.12.2009 Using the ‘line-of-balance’ programming technique to manage projects.   N/A
09.12.2009 Changes to the Civil Procedure Rules, in particular Part 35 and Practice Direction 35 relevant to experts and assessors.   N/A
02.12.2009 The factors that the Court will consider in determining what legal costs a successful litigant may recover.   Costain Limited v Charles Haswell & Partners Limited [2009] EWHC B25 (TCC)
25.11.2009 Avoidance of insurance policy cover   Laker Vent Engineering Limited -v- Templeton Insurance Limited QBD (Merc) 2008 and [2009] EWCA Civ 62
18.11.2009 Using the ‘S curve’ method for demonstrating delay to a construction project.   N/A
11.11.2009 Clarity in the nature of the redress sought in relation to payment.   Rok Building Limited –v– Celtic Composting Systems Limited [2009] EWHC 2664 (TCC), 30 October 2009
04.11.2009 What factors need to be considered in determining the extent of critical delay to be used as a basis for the calculation of prolongation costs?   Costain Limited v Charles Haswell and Partners Limited [2009] EWHC B25 (TCC)
28.10.2009 Consultants’ liability to contractors for negligent misstatements.   J Jarvis & Sons Ltd -v- (1) Castle Wharf Developments Ltd (2) Gleeds Management Services Ltd (3) Franklin Ellis Architects Ltd [2001] EWCA Civ 19
21.10.2009 Using the ‘Windows Analysis’ method for demonstrating delay to a construction project.   N/A
14.10.2009 The effect of a failure of contract payment conditions to take account of a change in insolvency law in 2002.   William Hare Limited v Shepherd Construction Limited [2009] EWHC 1603 (TCC), 25 June 2009
07.10.2009 Measure of damages for defects.   Albert Bartlett & Sons (Airdrie) Limited v Gilchrist & Lynn Limited & Others [2009] CSOH 125
30.09.2009 Consultants’ tortious liability to contractors to prevent them under pricing.   Galliford Try Infrastructure Ltd (formerly (a) Morrison Construction Ltd and (b) Morrison Construction Services Ltd) -v- Mott MacDonald Ltd and Rowen Structures Ltd
23.09.2009 Using the ‘Time-Impact’ method of delay analysis for demonstrating delay to a construction project.   N/A
16.09.2009 Whether the ground for withholding has to be valid for a withholding notice to be effective.   Windglass Windows Ltd -v- (1) Capital Skyline Construction Ltd (2) London and City Group Holdings Ltd [2009] EWHC 2022, 14 July 2009
09.09.2009 Remoteness of damage under contract.   Donoghue v Greater Glasgow Health Board [2009] CSOH 115
01.09.2009 Contractual and common law rights to termination.   Stocznia Gdynia SA -v- Gearbulk Holdings Ltd [2009] EWCA Civ 75
01.09.2009  
26.08.2009 The impact of the Limitation Act 1980 on adjudication decisions.   Jim Ennis Construction Limited v Premier Asphalt Limited [2009] EWHC 1906 (TCC), 24 July 2009
19.08.2009 Using the ‘Collapsed As-Built’ method of delay analysis for demonstrating delay to a construction project.   N/A
12.08.2009 What factors constitute a breach of the rules of natural justice in an adjudication?   Primus Build Ltd v Pompey Centre Limited and Slidesilver Limited [2009] EWHC 1487 (TCC)
05.08.2009 Contract formation and interpretation.   Fitzpatrick Contractors Ltd -v- Tyco Fire & Integrated Solutions (UK) Ltd [2008] EWHC 1301 (TCC)
28.07.2009 Using the ‘Impacted As-Planned’ or ‘As-Planned v As-Built’ methods of delay analysis for demonstrating delay to a construction project.   N/A
22.07.2009 The definition of construction operations under sections 105 (1) and 105 (2) of the Construction Act.   North Midland Construction Plc v A E & E Lentjes UK Limited (Formerly Lentjes UK Limited Formerly Lurgi (UK) Limited) (2009) EWHC 1371 (TCC), 18 May 2009
15.07.2009 Whether there are circumstances in which a mediator can be released from obligations of confidentiality found in a mediation agreement.   Farm Assist Limited (in liquidation) v The Secretary of State for the Environment, Food and Rural Affairs (No 2)
08.07.2009 Battle of the forms and contract formation.   A E Yates Trenchless Solutions Limited -v- Black & Veatch Limited [2008] EWHC 3183 (TCC)
01.07.2009 Using the total cost and productivity baseline methods for measuring a loss of productivity.   N/A
24.06.2009 Adjudicator’s jurisdiction to deal with counterclaims and requirement for withholding notices.   Letchworth Roofing Company v Sterling Building Company [2009] EWHC 1119 (TCC), 5 May 2009
17.06.2009 Whether interest can accrue under the Late Payment of Commercial Debts (Interest) Act 1998 in respect of unpaid incorrect invoices   Ruttle Plant Hire Limited v Secretary of State for Environment, Food and Rural Affairs [2009] EWCA Civ 97
10.06.2009 Joint names insurance and allocation of risk.   Tyco Fire & Integrated Solutions (UK) Ltd (Formerly Wormald Ansul (UK) Ltd) -v- Rolls-Royce Motor Cars Ltd (Formerly Hireaus Ltd) [2008] EWCA Civ 286
03.06.2009 Using the measured mile technique for measuring a loss of productivity.   N/A
27.05.2009 Spotting an adjudication in the making.  
20.05.2009 Whether a Net Contribution Clause would be subject to the Unfair Contract Terms Act 1977.   Langstane Housing Association Limited v Riverside Construction Aberdeen Limited and Others [2009] ScotCS CSOH_52
13.05.2009 Obligations concerning fitness for purpose and the duty to warn.   J Murphy & Sons Ltd -v- Johnston Precast Ltd (formerly Johnston Pipes Ltd) [2008] EWHC 3024 (TCC)
29.04.2009 Recognising the causes of a loss of productivity on a construction project.  
22.04.2009 Mandatory injunctions   Amec Group Limited v Universal Steels (Scotland) Limited [2009] EWHC 560 (TCC), 25 March 2009
15.04.2009 Whether an adjudicator can recover his fees from the responding party where that party raises questions of jurisdiction .   Christopher Michael Linnett v Halliwells LLP, EWHC 319 (TCC) 24.02.09
08.04.2009 Can invoices which have already been paid be reopened and/or can payments made be recovered?   Furmans Electrical Contractors -v- Elecref Ltd [2009] EWCA Civ 170
01.04.2009 Using recognised planning and programming practices and identifying poor ones.   N/A
25.03.2009 Whether the losing party in an adjudication can resist enforcement of an adjudicator’s decision in the event that the successful party becomes the subject of a Company Voluntary Arrangement.   Mead General Building Ltd v Dartmoor Properties Ltd [2009] EWHC 200 (TCC)
18.03.2009 Is a party irrevocably bound by its chosen course of action?   PT Building Services Limited -v- ROK Build Limited [2008] EWHC 3434 (TCC)
11.03.2009 Getting the balance right for the drafting and management of the construction programme.  
04.03.2009 Whether an adjudicator can determine the value of an interim payment when the notice of adjudication refers to a dispute about the final account.   OSC Building Services Limited v Interior Dimensions Contracts limited [2009] EWHC 248 (TCC), 8 January 2009
25.02.2009 Whether a stay of court proceedings will be granted where there is reference to an agreement to mediate in the underlying contract.   Balfour Beatty Construction Northern Limited v Modus Corovest (Blackpool) Limited [2008] EWHC 3029 (TCC)
18.02.2009 Recovery of overheads and profit.   Wraight Ltd v P.H. & T. (Holdings) Ltd 13 BLR 26
11.02.2009 Using prospective rather than retrospective delay analysis.   Don’t Look Back in Anger……
04.02.2009 The effect of determination on the enforceability of an adjudicator’s decision under the JCT Minor Works, 1998 Edition.   Westwood Structural Services Limited V Blyth Wood Park Management Company Limited [2008] EWHC 3138 (TCC), 9 December 2008
28.01.2009 Whether a responding party can raise defences in an adjudication which had not been rehearsed previously.   Quartzelec Limited v Honeywell Control Systems Limited TCC10908
21.01.2009 Whether an adjudicator’s decision can be resisted at enforcement stage if it concerns disputes arising from more than one contract.   Air Design (Kent) Limited v Deerglen (Jersey) Limited [2008] EWHC 3047(TCC)
14.01.2009 The actions that can be undertaken to reduce uncertainty in construction planning and programming.   Failure to Plan is a Plan for Failure